0001 Legal Notice

LEGAL NOTICE NOTICE TO BIDDERS

Sealed Bids will be received by the Village of West Lafayette , for furnishing the materials and performing the labor for the execution and construction of :

Water Works Park Public Restroom Project West Lafayette , Ohio

In accordance with the Plans and Specifications prepared by Diversified Engineering , Inc , 175 Ray Avenue NE , New Philadelphia , Ohio 44663 .

Facsimile and email proposals will not be accepted . Any proposed Equal for a Standard shall be submitted to the Engineer no later than five ( 5 ) business days prior to the bid opening . If no Addenda are issued in association with the bidder ' s request , the proposed equal shall be considered rejected .

Sealed bids will be received for : General Construction Prime Contract

Estimate of Probable Construction Cost : $ 43,000.00

Until : 10:00 a . m ., local time , on Thursday February 25 , 2021 at the West Lafayette Administrative Office , 113 East Railroad St ., West Lafayette , OH . 43845 after which they will be opened and read in public at approximately 11:00 am in council chambers . Please call 740-545-7834 to set up an appointment to drop off your sealed bid as the Administrative Offices are closed due to COVID 19 protocols . Please note : BIDS DELIVERED / RE- CEIVED AFTER THE SUBMITTAL TIME WILL NOT BE ACCEPTED .

A Pre-bid meeting for all interested contractors will be held on Monday , February 15 , 2021 at 9:00 am . in council chambers .

The Contractor responsible for scheduling the project , coordinating all sub-contractors and providing other services identified in the Contract Documents shall be the General Contractor , also named as the lead contractor .

Bid documents must be obtained from the Issuing Office below for the cost of printing . Only complete sets of drawings and specifications will be issued . No partial sets will be issued . All bidders are responsible for the content of the complete set of bid documents . Any bids received from a Bidder not on record as a purchaser of Bid Documents from the Issuing Office will be rejected and not opened .

Issuing Office : Diversified Engineering , Inc . 175 Ray Avenue , NE New Philadelphia , OH 44663

Bid Documents will be sold , shipped and distributed by Diversified Engineering , Inc . Cost of each set of Documents is $ 100 plus shipping costs . They can be reached by phone at ( 330 ) 364-1631 .

A Bid Guaranty , as required by ORC 153.54 , shall accompany each proposal in one of two forms , as follows :

A . A certified check or cashier ' s check in the amount equal to ten percent ( 10 %) of the total bid amount submitted with a signed Bid Guaranty form . Upon entering into a contract with the Owner , the successful Bidder must then file a performance bond for the full amount of the contract . Checks will be returned to the successful and unsuccessful Bidders when the contract is executed ; or after sixty ( 60 ) days . Checks are to be made payable to the Village of West Lafayette .

B . A Bid Guaranty and Contract Bond for the full amount of the Bid . The bond will be retained for the successful Bidder , but returned to the unsuccessful Bidders upon execution of the contract . If no contract award has been made within sixty ( 60 ) days after the opening of Bids , a Bidder may demand the return of the bid security provided the Bidder has not been notified of the acceptance of its Bid . Attorney-in-fact who sign contract bonds must file with each bond a certified copy of their power of attorney , properly dated . Checks should be made payable to the Village of West Lafayette . FAIL- URE TO SUBMIT A PROPER BOND WILL AUTOMATICALLY INVALID- ATE THE BID . If the successful Bidder fails to enter a contract or defaults in any portion of his / her bid the bid guarantee shall be forfeited as liquidated damages .

Submit your offer on the Bid Form provided . Bidders may supplement this form as appropriate . Signing of a Non-Collusion Affidavit and a Personal Property Tax Statement are to be included and returned with the bid . Please note the Village of West Lafayette is exempt from all Federal , State , Local and / or Excise Taxes .

Your offer will be required to be submitted under a condition of irrevocability for a period of 60 days after submission .

The Owner reserves the right to accept or reject any or all offers , to accept the lowest responsible bids , to waive any informalities in bids received . CCB : Feb 11 , 18 , 2021

LEGAL NOTICE The 2020 Bethlehem Township Annual Financial Report has been completed and available for the public to view by calling Tammy Pope , Fiscal Officer 740-824-4593 . CCB : Feb 11 , 2021

LEGAL NOTICE The 2020 Village of Warsaw Annual Financial Report has been completed and available for the public to view by calling 740-824-3600 . Tammy L Pope , Fiscal Officer . CCB : Feb 11 , 2021

LEGAL NOTICE Bethlehem Township will be holding their regular meetings for 2021 the last Wednesday of the month at 7:00PM at the township hall . We ask until further notice that visitors maintain 6ft apart and wear masks . CCB : Feb 11 , 2021

LEGAL NOTICE The monthly Pike Township Board of Trustees meeting will be held the second Monday of each month , 8:00PM at the Pike Township maintenance building , West Carlisle , OH . Susan Brinker , Fiscal Officer CCB : Feb 11 , 2021

LEGAL NOTICE Pursuant to Resolution # 2021-02 , the Village of West Lafayette , Ohio is offering for sale to the highest and best bidder the following items : 1 . 2000 Ford Ranger 2wd Reg Cab , 5 s p d m a n t r a n s , VIN # IFTYR10CXITA25481 2 . 1992 Ford Ranger 4wd Ext Cab , 5 s p d m a n t r a n s , VIN # TFTCR15X8PPA2392 3 . MX Power # 50EX Shuttle Diesel Front End Load Tractor with Bucket and Brush Hog 4 . Agri-Fab Leaf machine # CR750 5 . Deluxe Edger Trimmer # 6002 6 . Two Husqvarna Push Mowers # 550EX 7 . Two Husqvarna Weed Eaters # 322L The items may be viewed at the Village of West Lafayette , Ohio Administration Building ; Monday through Friday between 8:00 am and 3:00 pm .

Complete specifications are on file at the Village Administration Office , 113 East Railroad Street , West Lafayette , Ohio 43845 . Interested bidders must call , 740-545-5434 to schedule an appointment to view the items . The items are being sold as is , where is , and without warranty . The successful bidder shall be responsible for delivery .

The estimated value exceeds One Thousand Dollars ($ 1,000.00 ) and a minimum bid for the 2000 Ford Ranger shall be required of no less than One Thousand Dollars ($ 1,000.00 ) and a minimum bid for the 1992 Ford Ranger shall be required of no less than One Thousand Dollars ($ 1000.00 ) and a minimum bid for the MX Power Shuttle Tractor shall be required of no less than One Thousand Dollars ($ 1,000.00 ).

No other items for sale shall require a specified minimum bid amount . The SEALED bid shall be accompanied by a Ten Percent ( 10 %) certified bank check down payment which shall be returned to unsuccessful bidders . The Village reserves the right to reject any or all bids . The successful bidder shall pay to the Village the remaining amount due by certified bank check and shall take possession of the purchased item and remove it , within thirty ( 30 ) days of award of the bid . Bids shall be opened February 22 , 2021 during the regularly scheduled Village Council Meeting which commences at 7:00 pm and the purchase and sale or rejection of any or all bids shall be announced . A contract of sale shall be executed within seven ( 7 ) days of the award of the bid written . SEALED bids shall be received at the Village Administration Office , 113 East Railroad Street , West Lafayette , Ohio , until 3:00 p . m . on February 19 , 2021 . Bids received after the final date and time will be rejected . By order of the Village Administrator Christopher Menapace CCB : Feb 4 , 11 , 2021

LEGAL NOTICE The 2020 Annual Financial Report for Three Rivers Fire District is complete and available at the Fiscal Officer ’ s Office located at , 24199 SR 621 Coshocton , Ohio . Cindy L . Harrah , Fiscal Officer CCB : Feb 11 , 2021

LEGAL NOTICE The Bedford Township Board of Trustees will be holding their regular 2021 meetings on the last Thursday of each month at 7PM at the Township Hall in Tunnel Hill . Any questions please contact Jaime Hunt , Fiscal Officer at 740-502-8027 . CCB : Feb 11 , 2021

LEGAL NOTICE The Adams Township 2021 meetings will be held the third Tuesday of each month at 8 pm . The January meetings are the last Tuesday of the month . The 2020 financial report will be available for viewing after February 16 by contacting Heather Huff at 740-498-8231 . CCB : Feb 11 , 2021

LEGAL NOTICE ESTATE OF JOHN R . ARTER , JR . AKA JOHN ARTER , JR . DECEASED CASE NO . 20211018

“ TO ALL PERSONS INTERESTED IN THE ESTATE OF JOHN R . ARTER , JR . AKA JOHN ARTER , JR . , DE- CEASED , LATE OF 21465 CR 410 , WEST LAFAYETTE , OHIO 43845 , COSHOCTON COUNTY PROBATE COURT , CASE NO . 20211018 .

An application has been filed asking to relieve the estate from administration , saying that the assets do not exceed the statutory limits . A hearing on the application will be held March 9 , 2021 at 8:30 o ’ clock a . m . Persons knowing any reason why the application should not be granted should appear and inform the Court . The Court is located at 426 Main Street , Coshocton , Ohio , 43812 . VAN BLANCHARD II , Probate Judge

Diana E . Dudgeon , Esquire 201 N . Main Street , PO Box 272 Uhrichsville , Ohio 44683 CCB : Feb 11 , 18 , 25 , 2021

BF-00504052

Ram

LEGAL NOTICE Annual Financial Report for Lafayette Township The Annual Financial Report of Lafayette Township for the year ending December 31 , 2020 , has been completed and is available for public inspection . For information call Fiscal Officer , James Overholt at 545-6968 . CCB : Feb 11 , 2021

LEGAL NOTICE Ord 3-21 an ordinance authorizing the issuance of $ 1,145,000 of water and sewer system acquisition bonds , series 2021 , to retire notes previously issued in anticipation of such bonds , and declaring an emergency . Complete text of this ordinance may be obtained or viewed at the Clerk of Council Office , City of Coshocton . CCB : Feb 4 , 11 , 2021

LEGAL NOTICE The Coshocton Public Library Board of Trustees is soliciting annual statements of qualifications for professional design services , to include architecture , landscape architecture , engineering and surveying , for yet-to-be identified projects . The statements of qualifications should include : ( 1 ) information regarding the firm ’ s history ; ( 2 ) education and experience of owners and key personnel ; ( 3 ) competence to perform professional design services as indicated by the technical training , education , and experience of the firm ’ s personnel ; ( 4 ) ability of the firm in terms of its workload and the availability of qualified services competently and expeditiously ; ( 5 ) past performance of the firm as reflected by the evaluations of previous clients with respect to such factors as control of costs , quality of work , and meeting of deadlines ; and ( 6 ) past project examples ( 7 ) example of template used to build bid packet . Eight copies of statements of qualifications must be submitted to the following address or by email by 5:00p . m . local time on February 26 , 2021 . Jennifer Austin , Director jaustin @ coshoctonlibrary . org Coshocton Public Library 655 Main Street Coshocton , Ohio 43812 CCB : Feb 11 , 18 , 2021

LEGAL NOTICE The 2020 Annual Year End Financial Report for Washington Township has been completed and is available to view by contacting the Fiscal Officer , Toni L . Lee at 740-327-5121 . CCB : Feb 11 , 2021

LEGAL NOTICE To the following tenants at Schu-Stor , 52441 CR16 , West Lafayette , Ohio 43845 Jessica Gaines , 309 East 5th Street , West Lafayette , Ohio 43845 Scott McCoy , 744 Pine Street , Coshocton , Oho 43812 Robert Bridges , 137 West Main Street , West Lafayette , Ohio 43845 All personal property will be removed on March 7 , 2021 if not paid before that date . Any persons having any interest should contact Schu-Stor 740-622- 8915 concerning payment prior to eviction . CCB : Feb 11 , 18 , 2021

LEGAL NOTICE IN THE COSHOCTON COUNTY MUNICIPAL COURT LFP11 , LLC vs . William S . Burton , Unknown Spouse of William S . Burton , if any , Teresa L . Burton , Unknown Spouse of Teresa L . Burton , if any Case Number : CVH2100031

Attention : William S . Burton , Unknown Spouse of William S . Burton , if any , Teresa L . Burton , Unknown Spouse of Teresa L . Burton , if any . LFP11 , LLC (“ Plaintiff ”) has filed a complaint against you in Case Number CVH2100031 in the Municipal Court of Coshocton County to forfeit the land installment contract filed against Permanent Parcel Number : 043-00003155-00 . A full legal description of the parcel involved is contained in the Court ’ s file . You have twenty-eight days to file an answer or other responsive pleading with the Court from the date of last publication of this notice . If you fail to file an answer or other responsive pleading , the Court may grant the relief sought by the Plaintiff . The Attorney for the Plaintiff is William Todd Drown , 232 Chestnut Street , Coshocton , Ohio 43812 . 740-291- 8080 . Answer by date : March 11 , 2021 CCB : Jan 28 , Feb 4,11 , 2021

1921 Otsego Ave , Coshocton 740.622.3936 • 866.622.0207 www . jeffdrennen . com

( plus tax & shop fees )

WHAT WE DO : Inspect Brake System including brake lines . Also includes hoses , pads , caliper , wheel cylinders . Status condition of rotors and drums .

WHY WE DO IT : Ensures safe braking , prevents pesky brake pulsations and squeals . Extends the life of your brakes .

WHY WE CARE : Because your safety is our business !

CALL 740-622-3936 TO SET UP AN APPOINTMENT OR STOP IN AND SEE OUR SERVICE DEPARTMENT AT 1921 OTSEGO AVE . COSHOCTON

We want you to have a safe and reliable vehicle this winter ! Offer Expires : February 28 , 2021 .

NOT VALID WITH ANY OTHER OFFER . PRICES DO NOT INCLUDE SALES TAX OR SHOP SUPPLIES

A Bid Guaranty , as required by ORC 153.54 , shall accompany each proposal in one of two forms , as follows :